Appendix E: General Conditions
Attention: Update to terms and conditions
These terms and conditions apply only to contracts which were awarded prior to April 1, 2014, and contracts resulting from a Request for Proposal process issued prior to the same date.
GC1 Interpretation
1.1 In the contract,
1.1.1 "Canada", "Crown", "Her Majesty" or "the Government" means Her Majesty the Queen in right of Canada;
1.1.2 "Contract" means the contract documents referred to in the Articles of Agreement;
1.1.3 "Contract Price" means the amount expressed in the Contract to be payable to the Contractor for the Work;
1.1.4 "Contractor" means the person or entity whose name appears on the signature page of the written agreement and who is to supply goods or services to Canada under the Contract;
1.1.5 "Departmental Representative" means the officer or employee of Her Majesty who is designated by the Articles of Agreement and includes a person authorized by the Departmental Representative to perform any of the Departmental Representative's functions under the contract;
1.1.6 "Government Property" means all materials, parts, components, Specifications, equipment, software, articles and things supplied to the Contractor by or on behalf of Canada for the purposes of performing the Contract and anything acquired by the Contractor in any manner in connection with the Work the cost of which is paid by Canada under the Contract.
1.1.7 "Minister" means the Minister representing Her Majesty the Queen in this contract and includes a person acting for, or if the office is vacant, in place of the Minister and the Minister's successors in the office, and the Minister's or their lawful deputy and any of the Minister's or their representatives appointed for the purpose of the contract;
1.1.8 "Specifications" means the functional or technical description of the Work set out or referred to in the Contract, including drawings, samples and models, and further includes, except to the extent inconsistent with anything set out or referred to in the Contract, any such description set out or referred to in any brochure, product literature or other documentation furnished by the Contractor in relation to the Work or any part thereof;
1.1.9 "Subcontract" includes a contract let by any subcontractor at any tier for the performance or supply of a part of the Work, and the derivatives of the work shall be construed accordingly;
1.1.10 "Work", unless otherwise expressed in the contract, means everything that is necessary to be done, furnished or delivered by the Contractor to perform the Contractor's obligations under the contract.
1.2 In the contract, words importing the singular number include the plural and vice versa, and words importing the masculine gender include the feminine gender and the neuter.
1.3 The headings used in these general conditions are inserted for convenience of reference only and shall not affect their interpretation.
GC2 Successors and assigns
2.1 The Contract shall enure to the benefit of, and shall be binding upon, the successors and permitted assignees of Canada and of the Contractor.
GC3 Assignment
3.1 The Contract shall not be assigned in whole or in part by the Contractor without the prior written consent of the Minister and any assignment made without that consent is void and of no effect.
3.2 No assignment of the Contract shall relieve the Contractor from any obligation under the contract or impose any liability upon Her Majesty or the Minister unless otherwise agreed to in writing by the Minister.
GC4 Time of the essence
4.1 Time is of the essence of the contract.
GC5 Excusable delay
5.1 A delay in the performance by the Contractor of any obligation under the Contract which is caused solely by an event that
- was beyond the reasonable control of the Contractor,
- could not reasonably have been foreseen,
- could not reasonably have been prevented by means reasonably available to the Contractor, and
- occurred without the fault or neglect of the Contractor shall, subject to subsections 5.2, 5.3 and 5.4 constitute an "Excusable Delay" provided that the Contractor invokes this section by notice under subsection 5.4.
5.2 If any delay in the Contractor's performance of any obligation under the Contract is caused by a delay of a Subcontractor, such a delay may constitute an Excusable Delay for the Contractor, but only if the delay of the Subcontractor meets the criteria set out in this section for an Excusable Delay by the Contractor and only to the extent that the delay has not been contributed to by the Contractor.
5.3 Notwithstanding subsection 5.1, any delay caused by lack of financial resources of the Contractor or an event that is a ground for termination provided for in subsection 11.2 (Termination due to default of the Contractor), or any delay in the Contractor fulfilling an obligation to deliver a bond, guarantee, letter of credit or other security relating to performance or the payment of money, shall not qualify as an Excusable Delay.
5.4 The Contractor shall not benefit from an Excusable Delay unless the Contractor has:
- used its best efforts to minimize the delay and recover lost time;
- advised the Minister of the occurrence of the delay or of the likelihood of a delay occurring as soon as the Contractor has become aware of it;
- within 15 working days of the beginning of a delay or of the likelihood of a delay coming to the attention of the Contractor, advised the Minister of the full facts or matters giving rise to the delay, and provided to the Minister for approval (which approval shall not be unreasonably withheld) a clear "work-around" plan indicating in detail the steps that the Contractor proposes to take in order to minimize the impact of the event causing the delay; this plan shall include alternative sources of materials and labour, if the event causing the delay involves the supply of them; and
- carried out the work-around plan approved by the Minister.
5.5 In the event of an Excusable Delay, any delivery date or other date that is directly affected shall be postponed for a reasonable time not to exceed the duration of the Excusable Delay. The Parties shall amend the Contract, as appropriate, to reflect any such change in dates.
5.6 Notwithstanding subsection 5.5, the Minister may, after an Excusable Delay has continued for 30 days or more, in the Minister's absolute discretion terminate the Contract. In such a case, the Parties agree that neither will make any claim against the other for damages, costs, expected profits or any other loss arising out of the termination or the event that gave rise to the Excusable Delay. The Contractor agrees to repay immediately to Canada the portion of any advance payment that is unliquidated at the date of the termination. Subsections 11.4, 11.5 and 11.6 (Termination due to default of the Contractor) apply in the event of a termination under this subsection.
5.7 Except to the extent that Canada is responsible for the delay for reasons of failure to meet an obligation under the Contract, Canada shall not be liable for any costs or charges of any nature incurred by the Contractor or any of its subcontractors or agents as a result of an Excusable Delay.
GC6 Indemnification
6.1 The Contractor shall indemnify and save harmless Canada, the Minister and their servants and agents from and against any damages, costs or expenses or any claim, action, suit or other proceeding which they or any of them may at any time incur or suffer as a result of or arising out of
- any injury to persons (including injuries resulting in death) or loss of or damage to property of others which may be or be alleged to be caused by or suffered as a result of the performance of the Work or any part thereof, except that Canada and the Minister shall not claim indemnity under this section to the extent that the injury, loss or damage has been caused by Canada, and
- any liens, attachments, charges or other encumbrances or claims upon or in respect of any materials, parts, work-in-process or finished work furnished to, or in respect of which any payment has been made by, Canada.
6.2 The Minister shall give notice to the Contractor of any claim, action, suit or proceeding referred to in subsection 6.1 and the Contractor shall, to the extent requested by the Attorney General of Canada, at its own expense participate in or conduct the defence of any such claim, action, suit or proceeding and any negotiations for settlement of the same, but the Contractor shall not be liable to indemnify Canada for payment of any settlement unless it has consented to the settlement.
GC7 Notices
7.1 Any notice shall be in writing and may be delivered by hand or by courier, by registered mail, or by facsimile or other electronic means that provides a paper record of the text of the notice, addressed to the Party for whom it is intended at the address in the Contract or at the last address of which the sender has received notice in accordance with this section. Any notice shall be deemed to be effective on the day it is received at that address.
GC8 Royalties and infringement
8.1 In this section, "Royalties" includes
- license fees and all other payments analogous to royalties for, and also claims for damages based upon, the use or infringement of any patent, registered industrial design, trade mark, copyrighted work, trade secret, or other intellectual property right, and
- any costs or expenses incurred as a result of the exercise by any person of Moral Rights.
8.2 The Contractor shall indemnify and save harmless Canada, the Minister and their servants and agents against any claim, action, suit or other proceeding for the payment of Royalties, that results from or is alleged to result from the carrying out of the Contract or the use or disposal by Canada of anything furnished by the Contractor under the Contract.
8.3 The Contractor shall notify the Minister of all Royalties which it or any of its subcontractors will or may be obligated to pay or propose to pay in respect of carrying out the Contract, and the basis thereof, and the parties to whom the same are payable, and shall promptly advise the Minister of any and all claims which would or might result in further or different payments by way of Royalties being made by the Contractor or any of its subcontractors.
8.4 Where and to the extent that the Minister so directs, the Contractor shall not pay and shall direct its subcontractors not to pay any Royalties in respect of the carrying out of the Contract.
GC9 Suspension of the work
9.1 The Minister may at any time, by written notice, order the Contractor to suspend or stop all or part of the Work under the Contract for a period of up to 180 days. The Contractor shall immediately comply with any such order in the manner that minimizes the cost of so doing. While such an order is in effect, the Contractor shall not remove any part of the Work from any premises without the prior written consent of the Minister. At any time prior to the expiration of the 180 days, the Minister shall either rescind the order or terminate the Contract, in whole or in part, under section GC10 (Termination for Convenience) or GC11 (Termination due to Default of Contractor).
9.2 When an order is made under subsection 9.1, unless the Minister terminates the Contract due to default of the Contractor or the Contractor abandons the Contract, the Contractor shall be entitled to be paid its additional costs incurred as a result of the suspension plus a fair and reasonable profit thereon.
9.3 When an order is made under subsection 9.1 and is rescinded:
- the Contractor shall as soon as practicable resume work in accordance with the Contract;
- if the suspension has affected the Contractor's ability to meet any delivery date under the Contract, the date for the performance of that part of the Work affected by the suspension shall be extended for a period equal to the period of suspension plus a period, if any, which in the opinion of the Minister following consultation with the Contractor is reasonably necessary for the Contractor to resume the Work; and
- subject to section GC18 (Amendments and Waivers), an equitable adjustment shall be made as necessary to affected terms and conditions of the Contract.
GC10 Termination for convenience
10.1 Notwithstanding anything contained in the Contract, the Minister may, at any time prior to the completion of the Work, by giving notice to the Contractor (in this section sometimes referred to as a "termination notice"), terminate the Contract as regards all or any part of the Work not completed. Upon a termination notice being given, the Contractor shall cease work in accordance with and to the extent specified in the notice, but shall proceed to complete such part or parts of the Work as are not affected by the termination notice. The Minister may, at any time or from time to time, give one or more additional termination notices with respect to any or all parts of the Work not terminated by any previous termination notice.
10.2 In the event of a termination notice being given pursuant to subsection 10.1, the Contractor shall be entitled to be paid, to the extent that costs have been reasonably and properly incurred for purposes of performing the Contract and to the extent that the Contractor has not already been so paid or reimbursed by Canada including the unliquidated portion of any advance payment:
- on the basis of the Contract Price, for all completed work that is inspected and accepted in accordance with the Contract, whether completed before, or after and in compliance with the instructions contained in, the termination notice;
- the cost to the Contractor plus a fair and reasonable profit thereon, for all work terminated by the termination notice before completion, the cost to the Contractor being determined in accordance with the terms of the Contract;
- the amount of any capital expenditures actually incurred only if they were specifically authorized under the Contract or approved in writing by the Minister for the purpose of the Contract, less any depreciation in respect thereof already taken into account in determining cost, to the extent that the capital expenditures are properly apportionable to the performance of the Contract;
- all costs of and incidental to the termination of the Work or part thereof, including the cost of cancellation of obligations incurred by the Contractor with respect to the terminated work or part thereof, the cost of and incidental to the taking of an inventory of materials, components, work-in-process and finished work on hand related to the Contract at the date of the termination, and the cost of preparation of necessary accounts and statements with respect to Work performed to the effective date of the termination and commitments made by the Contractor with respect to the terminated portions of the Work; but not including the cost of severance payments or damages to employees whose services are no longer required by reason of the termination except wages that the Contractor is obligated by statute to pay them and except for reasonable severance payments or damages paid to employees hired to perform the Contract whose hiring was expressly required by the Contract or approved in writing by the Minister for the purpose of the Contract.
10.3 In paragraph 10.2(c), "capital expenditures" includes the entry into leases of real property and equipment.
10.4 The Minister may reduce the payment in respect of any of the Work to the extent that, upon inspection, it is deficient in meeting the requirements of the Contract.
10.5 Notwithstanding anything in subsection 10.2, the total of the amounts to which the Contractor is entitled under paragraphs 10.2(a) to (c) inclusive, together with any amounts paid or due or becoming due to the Contractor under other provisions of the Contract, shall not exceed the Contract Price or the portion thereof that is applicable to the part of the Work that is terminated, and shall not exceed the proportion of the price quoted by the Contractor for all of the Work that is reasonably attributable to the proportion of the Work performed to the effective date of the termination.
10.6 In the procuring of materials and parts required for the performance of the Contract and in the subcontracting of any of the Work, the Contractor shall, unless otherwise authorized by the Minister, place purchase orders and subcontracts on terms that will enable the Contractor to terminate the same upon terms and conditions similar in effect to those provided in this section, and generally the Contractor shall co-operate with the Minister and do everything reasonably within its power at all times to minimize the amount of Canada's obligations in the event of a termination under this section.
10.7 Title to all material, equipment, work-in-process and finished work in respect of which payment is made to the Contractor shall, upon such payment being made, pass to and vest in Canada unless already so vested under any other provision of the Contract, and such material, equipment, work-in-process and finished work shall be delivered according to the order of the Minister, but Canada will not accept and will not pay for material, equipment or work-in-process that would not have been required to perform the Work or that exceed what would have been required to perform the Work.
10.8 The Contractor shall have no claim for damages, compensation, loss of profit, allowance or otherwise by reason of, or directly or indirectly arising out of, any action taken or termination notice given by the Minister under this section, except to the extent that this section expressly provides.
GC11 Termination due to default of contractor
11.1 Where the Contractor is in default in carrying out any of its obligations under the Contract, the Minister may, upon giving written notice to the Contractor, terminate for default the whole or any part of the Contract, either immediately, or at the expiration of a cure period specified in the notice if the Contractor has not cured the default to the satisfaction of the Minister within that cure period.
11.2 Where the Contractor becomes bankrupt or insolvent, makes an assignment for the benefit of creditors, or takes the benefit of any statute relating to bankrupt or insolvent debtors, or where a receiver is appointed under a debt instrument or a receiving order is made against the Contractor, or an order is made or a resolution passed for the winding up of the Contractor, the Minister may, to the extent permitted by the laws of Canada, upon giving notice to the Contractor, immediately terminate for default the whole or any part of the Contract.
11.3 Upon the giving of a notice provided for in subsection 11.1 or 11.2, the Contractor shall have no claim for further payment other than as provided in this section, but shall be liable to Canada for any amounts, including milestone payments, paid by Canada and for all losses and damages which may be suffered by Canada by reason of the default or occurrence upon which the notice was based, including any increase in the cost incurred by Canada in procuring the Work from another source. The Contractor agrees to repay immediately to Canada the portion of any advance payment that is unliquidated at the date of the termination. Nothing in this section affects any obligation of Canada under the law to mitigate damages.
11.4 Upon termination of the Contract under this section, the Minister may require the Contractor to deliver to Canada, in the manner and to the extent directed by the Minister, any completed parts of the Work which have not been delivered and accepted prior to the termination and any material, equipment or work-in-process which the Contractor has acquired or produced specifically in the fulfilment of the Contract.
11.5 Subject to the deduction of any claim that Canada may have against the Contractor arising under the Contract or out of the termination, Canada shall pay or credit to the Contractor the value, determined on the basis of the Contract Price including the proportionate part of the Contractor's profit or fee included in the Contract Price, of all completed parts of the Work delivered to Canada pursuant to a direction under subsection 11.4 and accepted by Canada, and shall pay or credit to the Contractor the cost to the Contractor that the Minister considers reasonable in respect of all material, equipment or work-in-process delivered to Canada pursuant to a direction under subsection 11.4 and accepted by Canada, but in no event shall the aggregate of the amounts paid by Canada under the Contract to the date of termination and any amounts payable pursuant to this subsection exceed the Contract Price.
11.6 Title to all material, equipment, work-in-process and finished work in respect of which payment is made to the Contractor shall, upon such payment being made, pass to and vest in Canada unless already so vested under any other provision of the Contract, and such material, equipment, work-in-process and finished work shall be delivered according to the order of the Minister, but Canada will not accept and will not pay for material, equipment or work-in-process that would not have been required to perform the Work or that exceed what would have been required to perform the Work.
11.7 Where, subsequent to issuance of a notice pursuant to subsection 11.1, the Minister is satisfied that grounds did not exist for a termination under this section, the notice shall be deemed a notice of termination for convenience issued under section GC10 (Termination for Convenience).
GC12 Records to be kept by Contractor
12.1 The Contractor shall keep proper accounts and records of the cost of the work and of all expenditures or commitments made by the Contractor including the invoices, receipts and vouchers, which shall at reasonable times be open to audit and inspection by the authorized representatives of the Minister who may make copies and take extracts therefrom.
12.2 The Contractor shall afford facilities for audit and inspection and shall furnish the authorized representatives of the Minister with such information as the Minister or they may from time to time require with reference to the documents referred to herein.
12.3 The Contractor shall not dispose of the documents referred to herein without the written consent of the Minister, but shall preserve and keep them available for audit and inspection for such period of time as may be specified elsewhere in the contract or, in the absence of such specification, until the expiration of 6 years after final payment under this Contract or until the settlement of all outstanding claims and disputes, whichever is later.
GC13 Ownership of intellectual property including copyright
13.1 See appropriate clause on Appendix "A".
GC14 Conflict of interest
14.1 It is a term of this Contract that no individual, for whom the post-employment provisions of the Conflict of Interest Act, S.C. 2006, c. 9, s. 2 or the Values and Ethics Code for the Public Service apply, shall derive a direct benefit from this Contract unless that individual is in compliance with the applicable post-employment provisions.
GC15 Contractor status
15.1 This is a contract for the performance of a service and the Contractor is engaged under the contract as an independent contractor for the sole purpose of providing a service. Neither the Contractor nor any of the Contractor's personnel is engaged by the contract as an employee, servant or agent of Her Majesty. The Contractor agrees to be solely responsible for any and all payments and/or deductions required to be made including those required for Canada or Quebec Pension Plans, Unemployment Insurance, Worker's Compensation, or Income Tax.
GC16 Conduct of the work
16.1 The Contractor represents and warrants that:
- it is competent to perform the Work; and
- it has the necessary qualifications, including knowledge, skill and experience to perform the Work, together with the ability to use those qualifications effectively for that purpose.
16.2 Except for Government Property specifically provided for in the Contract, the Contractor shall supply everything necessary for the performance of the Work, including all the resources, facilities, labour and supervision, management, services, equipment, materials, drawings, technical data, technical assistance, engineering services, inspection and quality assurance procedures, and planning necessary to perform the Work.
16.3 The Contractor shall:
- carry out the Work in a diligent and efficient manner;
- select and employ on the Work a sufficient number of properly qualified personnel, provide efficient and effective inspection and quality control procedures and provide administration and other support to its employees to the extent necessary to properly carry out the work;
- perform the Work in accordance with standards of quality acceptable to the Minister and in full conformity with the Specifications and all the requirements of the Contract; and
- provide effective and efficient supervision to ensure that the quality of workmanship is as stated in the Contract.
16.4 The Work shall not be performed by any person who, in the opinion of the Minister, is incompetent or has been conducting himself/herself improperly.
16.5 The Contractor warrants that all services performed under this Contract will, at the time of acceptance, be free from defects in workmanship and conform to the requirements of this Contract. If the Contractor is required to correct or replace the Work or any portion thereof, it shall be at no cost to Canada, and any work corrected or replaced by the Contractor pursuant to this subsection shall be subject to all provisions of this Contract to the same extent as Work initially performed.
16.6 The Contractor shall adhere to the Minister's reasonable interpretation of the requirements of the Contract insofar as such an interpretation is not inconsistent with any other part of the Contract.
16.7 Unless the Minister orders the Work or part thereof to be suspended pursuant to section GC9 (Suspension of the Work), the Contractor shall not stop or suspend any part of the Work pending the settlement or resolution of any difference between the Parties arising out of the Contract.
16.8 The Contractor shall provide such reports on the performance of the Work as are required by the Contract and such other reports as may reasonably be required by the Minister.
16.9 The Contractor shall be fully responsible for performing the Work and Canada shall not be liable for any negative consequences or extra costs arising out of the Contractor's following any advice given by Canada, whether given without or upon invitation by the Contractor, unless the advice was provided to the Contractor in writing by Canada and was accompanied by a statement specifically relieving the Contractor of any responsibility for negative consequences or extra costs that might arise from following the advice.
GC17 Member of the House of Commons
17.1 No member of the House of Commons shall be admitted to any share or part of this contract or to any benefit to arise therefrom.
GC18 Amendments and waivers
18.1 No design change, modification to the Work, or amendment to the Contract shall be binding unless it is incorporated into the Contract by written amendment or design change memorandum executed by the authorized representatives of the Minister and of the Contractor.
18.2 While the Contractor may discuss any proposed changes or modifications to the scope of the Work with the Minister, Canada shall not be liable for the cost of any such change or modification until it has been incorporated into the Contract in accordance with subsection 18.1.
18.3 No waiver shall be valid, binding or affect the rights of the Parties unless it is made in writing by, in the case of a waiver by Her Majesty, the Minister and, in the case of a waiver by the Contractor, the authorized representative of the Contractor.
18.4 The waiver by a Party of a breach of any term or condition of the Contract shall not prevent the enforcement of that term or condition by that Party in the case of a subsequent breach, and shall not be deemed or construed a waiver of any subsequent breach.
GC19 Entire agreement
19.1 The Contract constitutes the entire and sole agreement between the parties with respect to the subject matter of the Contract and supersedes all previous negotiations, communications and other agreements, whether written or oral, relating to it, unless they are incorporated by reference in the Contract. There are no terms, covenants, representations, statements or conditions binding on the parties other than those contained in the Contract.
GC20 Powers of the minister
20.1 Every right, remedy, power and discretion vested in or acquired by Canada or the Minister under the Contract or by law shall be cumulative and non-exclusive.
GC21 Compliance with applicable laws
21.1 The Contractor shall comply with all laws applicable to the performance of the Work or any part thereof including, without limitation, all laws concerning health and labour conditions and the protection of the environment, and shall require compliance therewith by all of its subcontractors. Evidence of compliance with such laws shall be furnished by the Contractor to the Minister at such times as the Minister may reasonably request.
GC22 Subcontracting
22.1 Unless otherwise provided in the Contract, the Contractor shall obtain the consent of the Minister in writing prior to subcontracting or permitting the subcontracting of any portion of the Work at any tier.
22.2 Notwithstanding subsection 22.1, the Contractor may, without prior consent of the Minister, subcontract such portions of the Work as is customary in the carrying out of similar contracts.
22.3 In any subcontract, the Contractor shall, unless the Minister otherwise consents in writing, ensure that the subcontractor is bound by terms and conditions compatible with and, in the opinion of the Minister, not less favourable to Canada than the terms and conditions of the Contract. Deviations in any subcontract from the terms of the Contract, including any right of termination of the Contract, shall be entirely at the risk of the Contractor.
22.4 The Contractor is not obliged to seek consent to subcontracts specifically authorized in the Contract.
22.5 Any consent to a Subcontract shall not relieve the Contractor from its obligations under the Contract or be construed as authorizing any liability on the part of Canada or the Minister to a subcontractor.
GC23 Replacement of personnel
23.1 When specific persons have been named in the Contract as the persons who must perform the Work, the Contractor shall provide the services of the persons so named unless the Contractor is unable to do so for reasons beyond its control.
23.2 If, at any time, the Contractor is unable to provide the services of any specific person named in the Contract, it shall provide a replacement person who is of similar ability and attainment.
23.3 The Contractor shall, before replacing any specific person named in the Contract, provide notice in writing to the Minister containing:
- the reason for the removal of the named person from the Work;
- the name, qualifications and experience of the proposed replacement person; and
- proof that the person has the required security clearance granted by Canada, if applicable.
23.4 The Minister may order the removal from the Work of any such replacement person and the Contractor shall immediately remove the person from the Work and shall, in accordance with subsection 23.2 and paragraphs 23.3(b) and (c), secure a further replacement.
23.5 The fact that the Minister does not order the removal of a replacement person from the Work shall not relieve the Contractor from its responsibility to meet the requirements of the Contract.
GC24 Security and protection of the work
24.1 The Contractor shall keep confidential all information provided to the Contractor by or on behalf of Canada in connection with the Work, including any information that is confidential or proprietary to third parties, and all information conceived, developed or produced by the Contractor as part of the Work where copyright or any other intellectual property rights in such information (except a licence) vests in Canada under the Contract. The Contractor shall not disclose any such information to any person without the written permission of the Minister, except that the Contractor may disclose to a subcontractor authorized in accordance with section GC22 (Subcontracting) information necessary for the performance of the Subcontract, on the condition that the subcontractor agrees that it will be used solely for the purposes of such Subcontract. Information provided to the Contractor by or on behalf of Canada shall be used solely for the purpose of the Contract and shall remain the property of Canada or the third party, as the case may be. Unless the Contract otherwise expressly provides, the Contractor shall deliver to Canada all such information, together with every copy, draft, working paper and note thereof that contains such information, upon completion or termination of the Contract or at such earlier time as the Minister may require.
24.2 Subject to the Access to Information Act, R.S.C. 1985, c. A-1 and to any right of Canada under this Contract to release or disclose, Canada shall not release or disclose outside the Government of Canada any information delivered to Canada under the Contract that is proprietary to the Contractor or a Subcontractor.
24.3 The obligations of the Parties set out in this section do not apply to any information where the same information:
- is publicly available from a source other than the other Party; or
- is or becomes known to a Party from a source other than the other Party, except any source that is known to be under an obligation to the other Party not to disclose the information, or
- is developed by a Party without use of the information of the other Party.
24.4 Wherever practical, the Contractor shall mark or identify any proprietary information delivered to Canada under the Contract as "Property of the contractor, permitted Government uses defined under this contract", and Canada shall not be liable for any unauthorized use or disclosure of information that could have been so marked or identified and was not.
24.5 When the Contract, the Work, or any information referred to in subsection 24.1 is identified as Top secret, Secret, Confidential, or Protected by Canada, the Contractor shall at all times take all measures reasonably necessary for the safeguarding of the material so identified, including those set out in the Pwgsc Industrial Security Manual and its supplements and in the department's Security Policy and Procedures Manuel and any other instructions issued by the Minister.
24.6 Without limiting the generality of subsections 24.1 and 24.2, when the Contract, the Work, or any information referred to in subsection 1 is identified as Top secret, Secret, Confidential, or Protected by Canada, the Minister shall be entitled to inspect the Contractor's premises and the premises of a subcontractor at any tier for security purposes at any time during the term of the Contract, and the Contractor shall comply with, and ensure that any such subcontractor complies with, all written instructions issued by the Minister dealing with the material so identified, including any requirement that employees of the Contractor or of any such subcontractor execute and deliver declarations relating to reliability screenings, security clearances and other procedures.
24.7 Any proposed change in the security requirements after the effective date of the Contract that would involve a significant increase in cost to the Contractor shall require an amendment to the Contract under the provisions of section GC18 (Amendments and Waivers).
GC25 Inspection of the work
25.1 The Work and any and all parts thereof shall be subject to such inspection as the Minister or the Departmental Representative determines to be appropriate, consistent with the relevant provisions of the Contract, if any, prior to acceptance by Canada. The Minister or the Departmental Representative shall have access to the Work at any time during working hours where any part of the Work is being carried out and may make examinations and such tests of the Work as the Minister or the Departmental Representative may think fit. Should the Work or any part thereof not be in accordance with the requirements of the Contract, the Minister or the Departmental Representative shall have the right to reject the Work and require its correction or replacement at the Contractor's expense. The Minister or the Departmental Representative shall inform the Contractor of the reasons for any such rejection. Inspection by the Minister or the Departmental Representative shall not relieve the Contractor from responsibility to meet the requirements of the Contract.
GC26 Title
26.1 Except as otherwise provided in the Contract, and except as provided in subsection 26.2, title to the Work or any part thereof shall vest in Canada upon delivery and acceptance thereof by or on behalf of Canada.
26.2 Upon any payment being made to the Contractor in respect of the Work or any portion of the Work, either by way of progress payments or accountable advances or otherwise, title to the Work so paid for shall vest in and remain in Canada unless already so vested under any other provision of the Contract.
26.3 Notwithstanding any vesting of title referred to in this section and except as otherwise provided in the Contract, the risk of loss or damage to the Work or part thereof so vested shall remain with the Contractor until its delivery to Canada in accordance with the Contract.
26.4 Any vesting of title referred to in subsection 26.2 shall not constitute acceptance by Canada of the Work and shall not relieve the Contractor of its obligation to perform the Work in accordance with the Contract.
GC27 Government property
27.1 Unless otherwise provided in the Contract, all Government Property shall be used by the Contractor solely for the purpose of the Contract and shall remain the property of Canada, and the Contractor shall maintain adequate accounting records of all Government Property, and, whenever feasible, shall mark the same as being the property of Canada.
27.2 The Contractor shall take reasonable and proper care of all Government Property while the same is in, on, or about the plant and premises of the Contractor or otherwise in its possession or subject to its control, and shall be responsible for any loss or damage resulting from its failure to do so other than loss or damage caused by ordinary wear and tear.
27.3 All Government Property, except such as is installed or incorporated into the Work, shall, unless otherwise specifically provided in the Contract, be returned to Canada on demand.
27.4 At the time of completion of the Contract, and if requested by the Minister or the Departmental Representative, the Contractor shall provide an inventory of all Government Property relating to the Contract.
GC28 No bribe
28.1 The Contractor represents and covenants that no bribe, gift, benefit, or other inducement has been or will be paid, given, promised or offered directly or indirectly to any official or employee of Canada or to a member of the family of such a person, with a view to influencing the entry into the Contract or the administration of the Contract.
GC29 Survival
29.1 All of the Contractor's obligations of confidentiality and all of the Contractor's representations and warranties set out in the Contract as well as the provisions concerning Government Property, indemnity against third party claims, royalties and infringement, intellectual property rights and accounts and audit shall survive the expiry of the Contract or the termination of the Contract due to default of Contractor or the termination of the Contract for convenience, or pursuant to subsection GC5 (Excusable Delay), or by mutual consent, as shall any other provision of the Contract which, by the nature of the rights or obligations set out therein, might reasonably be expected to be intended to so survive.
GC30 Severability
30.1 If any provision of the Contract is declared by a court of competent jurisdiction to be invalid, illegal or unenforceable, such provision shall be severed from the Contract and all other provisions of the Contract shall remain in full force and effect.
GC31 Certification - Contingency fees
31.1 The Contractor certifies that it has not directly or indirectly paid or agreed to pay and covenants that it will not directly or indirectly pay a contingency fee for the solicitation, negotiation or obtaining of this Contract to any person other than an employee acting in the normal course of the employee's duties.
31.2 All accounts and records pertaining to payments of fees or other compensation for the solicitation, obtaining or negotiation of the Contract shall be subject to the Accounts and Audit provisions of the Contract.
31.3 If the Contractor certifies falsely under this section or is in default of the obligations contained therein, the Minister may either terminate this Contract for default in accordance with the termination due to default of Contractor provisions of the Contract or recover from the Contractor by way of reduction to the Contract Price or otherwise the full amount of the contingency fee.
31.4 In this section:
"contingency fee" means any payment or other compensation that is contingent upon or is calculated upon the basis of a degree of success in soliciting or obtaining a government contract or negotiating the whole or any part of its terms;
"employee" means a person with whom the Contractor has an employer/employee relationship;
"person" includes an individual or group of individuals, a corporation, a partnership, an organization and an association and, without restricting the generality of the foregoing, includes any individual who is required to file a return with the registrar pursuant to section 5 of the Lobbyist Registration Act, R.S. 1985 c.44 (4th Supplement) as the same may be amended from time to time.
Page details
- Date modified: